Difference between revisions of "Category:113 Construction Inspection Guidance for Contractor's Claims"

From Engineering_Policy_Guide
Jump to navigation Jump to search
m (Per CM, updated daily diary link)
m (Per CM, revised the Claims Process guidance.)
Line 1: Line 1:
 +
 
[[image:113.jpg|right|325px]]
 
[[image:113.jpg|right|325px]]
Assure the contractor that project personnel are available and willing at all times to discuss and give decisions on all questions that may arise concerning interpretation of the plans and specifications. When agreement cannot be reached at the resident engineer level, inform the district construction and materials engineer of the misunderstanding. If agreement cannot be reached at the district level, the disagreement should be referred to the State Construction and Materials Engineer, through the district engineer. Personnel of Construction and Materials are available to attend any discussion of problems and assist in settlement of disagreements. If questions or misunderstandings arise between the resident engineer and the contractor about established policy, design features or standardization of procedures, refer the matters to the district construction and materials engineer for a decision. In all cases immediately inform the contractor in writing of the final decision and that the problem may still be appealed to higher authority.
+
Assure the contractor that project personnel are available and willing at all times to discuss and give decisions on all questions that may arise concerning interpretation of the plans and specifications. When agreement cannot be reached at the resident engineer level, inform the District Construction and Materials Engineer of the misunderstanding. If agreement cannot be reached at the district level, the disagreement should be referred to the State Construction and Materials Engineer, through the District Engineer. Personnel of Construction and Materials are available to attend any discussion of problems and assist in settlement of disagreements. If questions arise between the resident engineer and the contractor about established policy, design features or standardization of procedures, refer the matters to the District Construction and Materials Engineer for a decision. In all cases, immediately inform the contractor in writing of the final decision and that the problem may still be appealed to higher authority.  
  
When it becomes evident that a claim will be filed, inform the district office at once and start preparation of a detailed record. Cover the situation in detail each day in the [http://epg.modot.mo.gov/forms/CM/AWP_CO_DailyDiary.doc resident engineer's diary] [[image:bulldozer.jpg|20px]].
+
When it becomes evident that a claim will be filed, inform the district office at once and start preparation of a detailed record. The RE should thoroughly document all conversations and circumstances involving the dispute. Cover the situation in detail each day in the [http://epg.modot.mo.gov/forms/CM/AWP_CO_DailyDiary.doc resident engineer's diary] [[image:bulldozer.jpg|20px]].
  
The following are guidelines that shall be followed by contractors in filing a claim with
+
The following are guidelines that shall be followed by contractors in filing a claim with the Secretary of the Commission.
the Secretary of the Commission.
 
  
 
===113.1 Procedures for Handling Contractor Claims===
 
===113.1 Procedures for Handling Contractor Claims===
  
:'''1.''' The claim is received by the Commission Secretary, logged in, and forwarded to Construction and Materials. The division is responsible for providing all required reports and other documents to the Claims Committee, which is comprised of the Chief Engineer, Chair; Asst. Chief Engineer, Vice Chair; and the Chief Financial Officer.
+
'''1.''' The claim is received by the Commission Secretary, logged in, and forwarded to Construction and Materials Division. The division is responsible for providing all required reports and other documents to the Claims Committee, which is comprised of the Asst. Chief Engineer - Chair, Chief Financial Officer, and a District Engineer appointed by the Asst. Chief Engineer.
 
[[image:113.1.jpg|right|250px]]
 
[[image:113.1.jpg|right|250px]]
:'''2.''' The division reviews the claim for compliance with specifications and may consult with the Chief Counsel’s Office (CCO) regarding compliance with specifications relating to timely filing and sufficiency of the claim documents submitted.
+
'''2.''' CM Division reviews the claim for compliance with specifications and may consult with the Chief Counsel’s Office (CCO) regarding compliance with specifications relating to timely filing and sufficiency of the claim documents submitted.
  
:The division provides a preliminary copy of the claim to the CCO and the Office of Audits and Investigations to facilitate this review.
+
The division provides a preliminary copy of the claim to the CCO and the Audits and Investigations Division (AI) to facilitate this review as a notice of issue and for informational purposes.  CM will continue to evaluate if further evaluation is needed by AI or CCO.  In all cases of federally funded projects, the Federal Highway Administration (FHWA) will be provided a copy of the claim and the letter to the contractor.
  
:'''3.''' If the claim is accepted, the division assigns a claim number (year, sequential number, district; example: 03-01-07) and assigns the claim to a claim reviewer (Reviewer) in the division for review and evaluation. The claims reviewer is a Construction and Materials Liaison Engineer who has no previous extensive involvement with the issues presented in the claim. The liaison engineer’s goal is to provide an independent review of the facts and merit of the claim. The reviewer maintains all correspondence and documentation associated with the assigned claim. Copies of all claim related correspondence between MoDOT and the contractor are provided to MoDOT’s counsel assigned to the claim.
+
'''3.''' If the claim is accepted by the Commission, the division assigns a claim number (year, sequential number, district; example: 03-01-07) and assigns the claim to a claim reviewer (Reviewer) in the CM Division for review and evaluation. The claims reviewer is a Construction and Materials Liaison Engineer who has no previous extensive involvement with the issues presented in the claim. The liaison engineer’s goal is to provide an independent review of the facts and merit of the claim. The reviewer maintains all correspondence and documentation associated with the assigned claim.  
  
:The claim number is used in all references and correspondence regarding the claim. The division advises the contractor by letter if the claim has been accepted and provides the contractor with the claim number and the reviewer’s name. If the claim is not accepted, the division advises the contractor by letter citing the reason(s) the claim was not accepted, and provides a copy of the letter to the CCO and AI.
+
CM Division advises the contractor by letter if the claim has been accepted and provides the contractor with the claim number and the reviewer’s name. If the claim is not accepted, CM Division advises the contractor by letter citing the reason(s) the claim was not accepted and provides a copy of the letter to the CCO and AI.
  
:Claims and Controversies that qualify for Arbitration or Mediation must complete the review process including final notification to the contractor within ninety days from date of receipt by the Commission Secretary. At that point the contractor is eligible to submit these issues to binding arbitration or mediation. For claims with amounts that exceed the amounts provided by the Arbitration and Mediation laws, the State Construction and Materials Engineer may extend the time for review in order to provide time to adequately review the claim. The review of these claims should not extend beyond twelve months.  
+
When notification of a claim is received the district personnel and Resident Engineers office should not discuss the claim with any outside parties. Any inquiries should be referred to the Chief Counsels office. All appropriate files, diaries, records, etc. should be assembled and stored in a safe location at the project office or district office.
  
:The following time lines will apply to the normal claims process:
+
'''4.''' Claims and controversies that qualify for Arbitration or Mediation (Sec 105) must complete the review process including final notification to the contractor within ninety days from date of receipt by the Commission Secretary. At that point the contractor is eligible to submit these issues to binding arbitration or mediation. For claims that exceed the amounts provided by the Arbitration and Mediation laws, the State Construction and Materials Engineer may extend the time for review in order to provide time to adequately review the claim. The review of these claims should not extend beyond twelve months.
  
::a) The division shall notify the contractor of acceptance or denial of the claim upon completion of a review of the claim and supporting documentation for compliance with the requirements listed in the Missouri Standard Specifications for Highway Construction.
+
'''5.''' The following time lines will apply to the normal claims process:
::b) The district will submit the District Report on or before the date set by the division. A maximum of 28 calendar days will be allowed from the date of the letter of acceptance to the contractor.
 
::c) The reviewer will submit the Division Report within 5 working days of receipt of the district report.
 
::d) The division privileged report prepared by the State Construction & Materials Engineer will be completed within 7 calendar days of receipt of the Division Report. This report will be provided to the Claims Committee immediately upon completion.
 
::e) The Claims Committee meeting will be held no later than 45 calendar days after acceptance as a valid claim.
 
  
:'''4.''' The division furnishes each member of the Claims Committee a claim notebook containing a copy of the claim, the letter to the contractor, and all required reports and documents related to the claim. In all cases of federally funded projects, the Federal Highway Administration (FHWA) will be provided a copy of the claim and the letter to the contractor.
+
:'''a)''' CM shall notify the contractor of acceptance or denial of the claim upon completion of a review.  
  
:'''5.''' The reviewer will discuss the amount and complexity of the claim with the attorney assigned by the Chief Counsel’s Office (CCO) for preliminary advice on investigation. The reviewer will make a recommendation to the Claims Committee on the need to retain a consultant and the need to audit the claim. The reviewer may seek advice from the CCO and the Audits and Investigation (AI) prior to making a recommendation to audit the claim. The need for an audit will be based on the complexity of the claim and the scope, expertise and cost associated with the recommended audit. The Claims Committee votes whether to retain a consultant and perform an audit. If a consultant is retained, the reviewer coordinates the activities of the consultant and all department offices involved regarding the claim. The assigned reviewer in consultation with assigned counsel and project personnel will determine additional construction records required to investigate the claim and make formal, written request for them. If the contractor bid records have been escrowed, the escrow will be opened and documents obtained in accordance with the contract.
+
:The reviewer will meet with the contractor for the purposes of clarifying the claim and developing a better understanding of the contractor’s position regarding the claim. If required, a written request for the additional records will be made. If after this initial meeting with the contractor, the assigned reviewer determines there are grounds for a negotiated contract adjustment, the reviewer will obtain approval from the State Construction and Materials Engineer to proceed with the negotiations.  This meeting should take place within 28 days of the acceptance of the claim.
  
:'''6.''' The division prepares a letter to the district, furnishing two copies of the claim (one for the District Construction & Materials Engineer and one for the Resident Engineer) for investigation and requests the district report to be submitted by a specific date. The district is further advised to retain all project records and keep them in a separate filing unit. The district report Is prepared by the district office in consultation with the Resident Engineer Office directly associated with the claim. With a copy of the letter to the district, the Controller’s Office is advised that a claim has been filed and that project records should be left open until further notice and the records clerk in the division and other affected units are advised to retain all project records and keep them in a separate file unit.  
+
:'''b)''' CM prepares a letter to the district, furnishing two copies of the claim (one for the District Construction and Materials Engineer and one for the Resident Engineer) for investigation and requests the district report to be submitted by a specific date. The district is further advised to retain all project records. The district report is prepared by the District Construction and Materials Engineer in consultation with the Resident Engineer Office directly associated with the claim. For claims on projects that have not been finalized, no adjustments to disputed items or time for completion of the subject project may be made without prior agreement with the State Construction and Materials Engineer.
  
:For claims on projects that have not been finalized, no adjustments to disputed items or time for completion of the subject project may be made without prior agreement with the State Construction and Materials Engineer.
+
:In concert, the district and resident engineer are to review the claim and provide both a report on the facts of the claim and a separate recommendation regarding settlement to the State Construction and Materials Engineer with 28 days of the date of acceptance of the claim.
  
:In concert, the district and resident engineer are to review the claim and provide both a report on the facts of the claim and a separate recommendation regarding settlement to the State Construction and Materials Engineer with 28 days of the date of acceptance of the claim. The first report contains a factual analysis of the claim with no recommendation regarding disposition. This report should answer the claim in the same order or format as presented by the contractor. This is so that each allegation and response can be compared side by side. All allegations made by the contractor should be responded to. The second report is a recommendation regarding disposition of the individual items in the claim.
+
:'''c)''' The district will submit the District Report to the claims reviewer on or before the date set by the division. A maximum of 28 calendar days will be allowed from the date of the letter of acceptance to the contractor. The first part of the report contains a factual analysis of the claim with no recommendation regarding disposition. This report should answer the claim in the same order or format as presented by the contractor. This is so that each allegation and response can be compared side by side. All allegations made by the contractor should be responded to. The second part of the report is a recommendation regarding disposition of the individual items in the claim.
  
:'''7.''' The reviewer will contact the contractor to meet for the purposes of clarifying the claim and developing a better understanding of the contractor’s position regarding the claim. The reviewer and the District Construction & Materials Engineer will be MoDOT’s representatives at this meeting. If after this initial meeting with the contractor, the assigned reviewer determines there are grounds for negotiated contract adjustment, the reviewer will obtain approval from the State Construction & Materials Engineer to proceed with the negotiations. If necessary, the reviewer will ask questions for the purpose of clarification of contractor’s records previously obtained and identify further records needed and make informal request for the documents. If required, a written request for the additional records will be made. All negotiated contract adjustments must be approved as set out in item 15 of these procedures.
+
:The reviewer will meet with the district to listen to their version of events after receiving the District Report. This meeting should be held after the contractor meeting. This should happen within 2 weeks after receiving the District Report.
  
:'''8.''' The reviewer reviews the reports and prepares a separate report for the division with a copy to the assigned attorney.
+
:'''d)''' The reviewer will discuss the amount and complexity of the claim with the attorney assigned by the CCO for preliminary advice on additional research or evaluation is needed before proceeding.  The reviewer will submit the Division Report within two weeks after the meeting with the district.
  
:'''9.''' The division prepares a privileged report for the Claims Committee summarizing the information contained in the district and reviewer reports.
+
:'''e)''' The division final report prepared by the State Construction and Materials Engineer will be completed within 5 calendar days of receipt of the reviewer’s report.  This report will be provided to the Claims Committee immediately upon completion.
  
:'''10.''' The contractor is invited by letter to meet with the Claims Committee. If the contractor elects to meet, a meeting is scheduled for the contractor to furnish additional information pertaining to the claim and to respond to questions from the Claims Committee. MoDOT personnel attending the claims committee meeting will be the reviewer, the Division State Engineer, a representative of the affected district (District Construction & Materials Engineer and /or Resident Engineer) and any other State Engineers that the Claims Committee Chair may deem necessary. In the presence of the contractor, the reviewer, the Division State Engineer, and the district representative will make oral presentations. The contractor may ask questions after the oral presentation. The Claims Committee will evaluate the contractor’s information and the information presented by MoDOT’s representatives. The Claims Committee will then make a decision regarding disposition of the claim (acceptance, partial acceptance, denial or the need for further deliberation) on the day of the meeting. The contractor will be given the option to remain in the building while the Claims Committee deliberates privately and will be advised of the Claims Committee’s decision if the individual remains. If the Claims Committee’s decision is to make an offer to resolve the contractor’s claim by negotiated contract adjustment, the reviewer and division engineer will determine the basis and amount of the proposed adjustment. If the Claims Committee approves the amount, the contractor will be advised by letter, prepared by the division, stating the basis and amount of the offered adjustment. If the Claims Committee decides to deny the claim or make a unilateral adjustment under the contract, the contractor will be advised by a letter prepared by the division. The Claims Committee Chair will sign each type of letter. Subject to limitations of authority provided elsewhere, the claims committee may act upon concurrence of any two of the whole membership of the committee. The Claims Committee has 7 days from the date of the last meeting with the contractor, the date of the Claims Committee meeting if the contractor elected not to attend; or the receipt of a required audit of the contractor documents, whichever occurs latest, to analyze all relevant material and render a final decision including any offer of a negotiated contract adjustment or directed equitable adjustment. The above letters will be reviewed by the CCO before mailing. All letters sent to the contractor will be sent by registered/overnight delivery mail.
+
:'''f)''' The Claims Committee meeting will be scheduled by the claims reviewer once the Claims Committee has received the Division Report.
  
:'''11.''' A copy of the letter of decision is furnished to each member of the Claims Committee and the appropriate district. The above letter will advise the contractor of the option for a final meeting.
+
:'''g)''' The contractor may have legal counsel present, but it is not required since this is not a legal proceeding.  MoDOT will have someone from CCO present at the meeting.  Their role is to advise the Claims Committed on the legal merits of the case.  They will not be presenting or asking questions at the presentation. MoDOT personnel attending the claims committee meeting will be the reviewer, the State Construction and Materials Engineer, a representative(s) of the affected district (District Construction and Materials Engineer and /or Resident Engineer) and any other State Engineers that the Claims Committee Chair may deem necessary.
  
:'''12.''' If requested by the contractor within 5 calendar days of the date of the letter of notification of the Claims Committee’s decision, a final meeting will be scheduled to give the contractor another opportunity to furnish any additional information pertinent to the claim.
+
:The contractor will present their case to the claims committee. In the presence of the contractor, the reviewer, and other personnel deemed necessary will make oral presentations. The contractor may ask questions after the oral presentation and present any additional information as they wish. The Claims Committee will evaluate the contractor’s information and the information presented by MoDOT’s representatives. The Claims Committee will then make a decision regarding disposition of the claim (acceptance, partial acceptance, denial or the need for further deliberation) on the day of the meeting. The contractor will be given the option to remain in the building while the Claims Committee deliberates privately and will be advised of the Claims Committee’s decision if the individual remains.
  
:'''13.''' If additional documents are requested from the contractor as a result of the initial investigation, the meeting with the contractor provided for in item 7, or the first or second Claims Committee meetings, the contractor will be allowed 14 calendar days from the date of notification to submit the requested documents. If the contractor will not or cannot provide the requested documents within the agreed time frame, the claim will be denied. The Claims Committee will notify the contractor of its final decision in a letter dated no more than 88 calendar days after acceptance as a valid claim.
+
:If the Claims Committee’s decision is to make an offer to resolve the contractor’s claim by negotiated contract adjustment, the reviewer and division engineer will determine the basis and amount of the proposed adjustment. If the Claims Committee approves the amount, the contractor will be advised by letter, prepared by the division, stating the basis and amount of the offered adjustment. If the Claims Committee decides to deny the claim or make a unilateral adjustment under the contract, the contractor will be advised by a letter prepared by the division. The Claims Committee Chair will sign each type of letter. Subject to Delegation of Authority limitations, noted in Commission policy, the claims committee may act upon concurrence of any two of the three member Claims Committee. The Claims Committee has 7 days from the date of the Claims Committee meeting to respond to the contractor with a final decision including any offer of a negotiated contract adjustment or directed equitable adjustment. The above letters will be reviewed by the CCO before mailing.
  
:'''14.''' Notes of meetings with the contractor; documents obtained, assembled or prepared for analysis of the claim; interviews with the department employees or third parties; reports of consultants and audits, whether by AI or an outside firm, of or concerning the claim; reports of MoDOT staff and of the CCO called for by this procedure; internal correspondence among MoDOT staff or between department staff and counsel concerning the claim; correspondence between MoDOT staff or counsel and consultants or outside auditors concerning a claim and notes or minutes of meetings, deliberations or notes of the Claims Committee are all considered to be documents prepared or activities conducted in anticipation of litigation, to be privileged communications or work product of MoDOT’s or Commission’s representatives and shall also be considered government predecisional memoranda.
+
'''6.''' The Commission policy on settlement of claims will outline authorization levels.
 
 
:'''15.''' The Chair of the Claims Committee and the Chief Financial Officer have authority to concurrently approve settlement of claims for $250,000.00 or less, with concurrence of a majority of the Claims Committee. The Chief Engineer and the Chief Financial Officer have authority to concurrently approve unilateral or negotiated contract adjustments of $1,000,000 or less, with concurrence of a majority of the Claims Committee.
 
 
 
:'''16.''' If the recommendation is in excess of $250,000.00, the Chair of the Claims Committee submits the final recommendation to the Chief Engineer and the Chief Financial Officer for their separate consideration and concurrence. Upon concurrence the assigned division advises the contractor of MoDOT’s final decision and recommendation. A copy of the letter is furnished to each member of the Claims Committee and the district. The letter is reviewed by the CCO before mailing.
 
 
 
:'''17.''' If the contractor provides written acceptance of the negotiated contract adjustment offer, the Controller’s Office is notified of the amount with appropriate documentation, and requested to process payment to the contractor. This completes the claim process.
 
 
 
:'''18.''' If the contractor notifies the department that they do not accept the final negotiated contract adjustment offer, or if the contractor does not respond by the date given in the settlement offer letter, the claim will be closed and any unilateral adjustment determined appropriate will be made.
 
 
 
:'''19.''' Upon resolution of a claim that results in an award to the contractor, either by action of the Claims Committee, by court action, or by negotiating, the division will submit information to the FHWA, if federal participation is desired. The information to the FHWA shall be in accordance with ATTACHMENT “A”.
 
  
 +
'''7.''' Upon resolution of a claim that results in an award to the contractor, either by action of the Claims Committee, by court action, or by negotiating, the division will submit information to the FHWA, if federal participation is desired. The information to the FHWA shall be in accordance with '''Attachment “A”'''.
 
====<center>Attachment “A”, CONTRACT CLAIM PROCEDURES</center>====  
 
====<center>Attachment “A”, CONTRACT CLAIM PROCEDURES</center>====  
 
{| border="1" class="wikitable" style="margin: 1em auto 1em auto"
 
{| border="1" class="wikitable" style="margin: 1em auto 1em auto"
Line 83: Line 70:
 
|}
 
|}
  
:When notification of a claim is received the district personnel and Resident Engineers office should not discuss the claim with any outside parties. Any inquiries should be  referred to the Chief Counsels office. All appropriate files, diaries, records, etc. should be assembled and stored in a safe location at the project office or district office.
+
'''8.''' If the contractor provides written acceptance of the negotiated contract adjustment offer, Financial Services is notified of the amount with appropriate documentation and requested to process payment to the contractor. This completes the claim process.
 
 
===113.2 Keeping Concerned Parties Advised===
 
 
 
Keep all concerned advised of the progress of the matter. There is an area in
 
SiteManager for recording disputes and/or claim information that may be used. (Contract
 
Administration- Contract Records-Disputes/Claims)
 
  
===113.3 Claim Files===
+
'''9.''' If the contractor notifies the department that they do not accept the final negotiated contract adjustment offer, or if the contractor does not respond by the date given in the settlement offer letter, the claim will be closed and any unilateral adjustment determined appropriate will be made.
  
When a formal claim is filed in accordance with [http://www.modot.org/business/standards_and_specs/SpecbookEPG.pdf#page=4 Sec 105.16], the district and resident engineer should establish a claim file. From that point on, interdepartmental correspondence relating strictly to the subject claim is to be filed in the claim folder and thereby will be considered confidential information in case of future litigation. Routine project records may have to be duplicated and placed in both the project and claim files. Construction and Materials will establish a Claim Tracking Record in the MoDOT Contractors Database. Portions of this tracking record are confidential attorney/client privileged information. The non-confidential portions are available to project office personnel to keep them updated on the status of the claim. Contact Construction and Materials if there are any questions concerning this procedure.
+
'''10.''' All notes and information gathered in the claims process are conducted in anticipation of litigation, to be privileged communications or work product of MoDOT’s or Commission’s representatives and shall also be considered government predecisional memoranda.
[[image:113.4.jpg|right|450px]]
 
===113.4 Claim Category Codes===
 
In general, Contractor claims include allegations of differing site, changed and or extra work, delays or errors. In fact, claims often allege multiple causes. To aid in identifying and tracking claims, appropriate codes from the following listing should be assigned to each claim. The general description of each code will aid in identifying relevance to any particular claim. Each claim should be coded in descending order of importance for all appropriate allegations. The codes to be used are:
 
  
:'''SD''' Differing Site – Subsurface or latent physical conditions at the site differing materially from those indicated in the contract, or unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in the work
+
===113.2 Dispute Resolution===
 
 
:'''W''' Changed or Extra Work - An item of work not provided for in the contract as awarded, but found essential to the satisfactory completion of the contract.
 
 
 
:'''D''' Delays - Use descriptive codes below
 
 
 
:'''DU''' Utility Delays – All delays associated with utilities.
 
 
 
:'''DA''' Access Delays – Delays associated with access to portions of the right of way.
 
 
 
:'''DM''' Administration Delays – Any delay associated with decisions by Engineer
 
 
 
:'''E''' Errors Misrepresentations in plans or errors in applying specifications.
 
 
 
:'''O''' Other Claims that fail to fall into any of the previous categories
 
 
 
===113.5 Contractor Claim and Dispute Resolution===
 
 
Most contractors prefer to resolve all requests for additional time and or money at the Resident Engineer/district level – as does MoDOT.  Should the contractor file a formal claim, the [[:Category:100 GENERAL#100.1.2.1 Contractor Claims Committee|Contractor Claims Committee]] reviews and makes a determination on the contractor’s claims.  Contractors must go through the claims process before they can file a lawsuit against MoDOT.
 
 
   
 
   
The first step in resolving a contractor dispute is to gather information. The RE should sit down with the contractor and review all the information related to the dispute. Go in with an open mind. Too often people come into this meeting to defend their position instead of truly listening to the other person’s perspective. Resist the temptation to argue points of dispute at this meeting. The purpose of this meeting is to gather information and not to litigate the issue. This may sounds basic, but it is invaluable when resolving conflicts because it helps to reveal the real issues.
+
The first step in resolving a contractor dispute is to gather information. The RE should sit down with the contractor and review all the information related to the dispute. Go in with an open mind. Too often people come into this meeting to defend their position instead of truly listening to the other person’s perspective. Resist the temptation to argue points of dispute at this meeting. The purpose of this meeting is to gather information and not to litigate the issue. This may sound basic, but it is invaluable when resolving conflicts because it helps to reveal the real issues.  
  
====113.5.1 Time-related Disputes====
+
====113.2.1 Time-Related Disputes====
If it is determined that there is time due to the contractor, then a method to determine the extent of time should be established. If it is a time delay, make sure the time adjustment is made immediately at the conclusion of the event that is being discussed. Do not wait until the end of the job to adjust days since contractors may be able to claim they incurred acceleration costs to complete the project by the original completion date. The time extension must be made by change order. Verbally telling the contractor is not binding and cannot be verified. A verbal commitment is not part of the official contract that the contractor must honor. Even if the contractor is ahead of schedule and will likely finish by the original completion date, the Resident Engineer will still need to write a change order for additional delays. Without a change order, the contractor may still claim acceleration costs.
+
If it is determined that there is time due to the contractor, then a method to determine the extent of time should be established. If it is a time delay, make sure the time adjustment is made immediately at the conclusion of the event that is being discussed. Do not wait until the end of the job to adjust days since contractors may be able to claim they incurred acceleration costs to complete the project by the original completion date. The time extension must be made by change order. Verbally telling the contractor is not binding and cannot be verified. A verbal commitment is not part of the official contract that the contractor must honor. Even if the contractor is ahead of schedule and will likely finish by the original completion date, the Resident Engineer will still need to write a change order for additional delays. Without a change order, the contractor may still claim acceleration costs.  
  
Suppose there is a hard commitment on a deadline that cannot be moved. If this is the case, compensation to accelerate the project must be negotiated. If that amount cannot initially be agreed upon, then an agreement on what is compensable should be established, as well as a mechanism to track it. Once again, regardless of where contractors may be on their schedule, they will need to be compensated for acceleration to make up the days that are owed by contract if it really occurred. Do not pay for acceleration unless increases in premium time or other unforced increases in cost can be proven.
+
Suppose there is a hard commitment on a deadline that cannot be moved. If this is the case, compensation to accelerate the project must be negotiated. If that amount cannot initially be agreed upon, then an agreement on what is compensable should be established, as well as a mechanism to track it. Once again, regardless of where contractors may be on their schedule, they will need to be compensated for acceleration to make up the days that are owed by contract if it really occurred. Do not pay for acceleration unless increases in premium time or other unforced increases in cost can be proven.  
  
 
Time extensions may also affect any milestones that are on a project.  These may need to be adjusted accordingly.   
 
Time extensions may also affect any milestones that are on a project.  These may need to be adjusted accordingly.   
 
      
 
      
Delays caused by utilities are generally excusable but never compensable. Simply stated, additional time can be allotted, but not additional money. Other delays such as plan errors, differing site conditions, etc. could be compensable. Extended delays may result in higher costs to the contractor. Examples are labor increases, material cost increases, extended traffic control maintenance, equipment rental costs and jobsite office expenses.   These delay costs can be extensive, especially on large-scale projects with high overhead and long periods of delays.   A delay may push a job into winter or other time periods where critical path work cannot be performed or productivity rates are lower. Besides requiring additional time, this can also lead to additional costs incurred related to the delay periods.
+
Delays caused by utilities are generally excusable but never compensable. Simply stated, additional time can be allotted, but not additional money. Other delays such as plan errors, differing site conditions, etc. could be compensable. Extended delays may result in higher costs to the contractor. Examples are labor increases, material cost increases, extended traffic control maintenance, equipment rental costs and jobsite office expenses. These delay costs can be extensive, especially on large-scale projects with high overhead and long periods of delays. A delay may push a job into winter or other time periods where critical path work cannot be performed or productivity rates are lower. Besides requiring additional time, this can also lead to additional costs incurred related to the delay periods.  
  
 
The important thing is to research and determine whether the delay really did result in costs.  Only verifiable, auditable costs should be considered.   
 
The important thing is to research and determine whether the delay really did result in costs.  Only verifiable, auditable costs should be considered.   
  
Delays are very costly. A quick resolution to issues causing the delay is the best way to insulate a project from a large delay claim. Paying a premium to mitigate a delay impact will likely be a better value than paying for a delay claim. When a change order involves settlement and final resolution of an issue with the contractor or when there are concerns that the issue may come up again in a claim or lawsuit, the following language is recommended as part of the change order documentation:  
+
Delays are very costly. A quick resolution to issues causing the delay is the best way to insulate a project from a large delay claim. Paying a premium to mitigate a delay impact will likely be a better value than paying for a delay claim. When a change order involves settlement and final resolution of an issue with the contractor or when there are concerns that the issue may come up again in a claim or lawsuit, the following language is recommended as part of the change order documentation:
  
:"The amount being paid to <Construction Company> in this Change Order represents a negotiated settlement and, as such, reflects payment of all claims of <Construction Company> and/or any of its subcontractors and suppliers direct and indirect, including all impacts there from starting from the date of execution of the contract until the execution by both parties of the Change Order. However, nothing in this Change Order affects <Construction Company>'s right to file a claim based on an occurrence after the date of this Change Order."  
+
:"The amount being paid to <Construction Company> in this Change Order represents a negotiated settlement and, as such, reflects payment of all claims of <Construction Company> and/or any of its subcontractors and suppliers direct and indirect, including all impacts therefrom starting from the date of execution of the contract until the execution by both parties of the Change Order. However, nothing in this Change Order affects <Construction Company>'s right to file a claim based on an occurrence after the date of this Change Order."  
  
Note: Do not include the last sentence if the change order is final.  
+
Note: Do not include the last sentence if the change order is final.
  
====113.5.2 Compensation Disputes====
+
====113.2.2 Compensation Disputes====
If there is compensation due and agreed upon, a change order should be issued immediately.  Any delay in payment could be subject to interest owed the contractor as a part of the [http://www.moga.mo.gov/mostatutes/chapters/chapText034.html Prompt Pay Act, RSMo 34.057] (which does not apply if there is a genuine dispute as to causation or amount). If there appears to be a pay dispute, begin keeping thorough records of labor, equipment and materials. It is very difficult to quantify this information after the fact.  
+
If there is compensation due and agreed upon, a change order should be issued immediately.  Any delay in payment could be subject to interest owed the contractor as a part of the [https://law.justia.com/codes/missouri/2018/title-iv/chapter-34/section-34.057/ Prompt Pay Act, RSMo 34.057] (which does not apply if there is a genuine dispute as to causation or amount). If there appears to be a pay dispute, begin keeping thorough records of labor, equipment and materials. It is very difficult to quantify this information after the fact.  
  
Resolution of the entire issue on a single change order is ideal. This prevents someone from repeatedly coming back to request compensation for an item believed to be resolved with other items. The contractor is always paid what the engineer believes is owed. MoDOT will not be penalized for any delay in verifying or resolving disputes. <u>Never</u> <u>pay</u> any amount that is a compromise figure without including in the change order documentation the recommended language found near the bottom of EPG 113.5.1 Time-related Disputes. Absence of this recommended language could impress a potential jury that the withheld amounts were held as undisputed hostage until the contractor capitulated on the remaining amount. Always be fair. If the contractors errantly do not request payment for something they are contractually owed, inquire why they did not. The goal is to pay what is contractually owed and not how little the issue can be resolved for. These good faith gestures will lead to a more timely resolution. This reduces time and expense for everyone and greatly reduces the likelihood that it will end up in litigation. Litigation is costly and time-consuming for all parties and should be a last resort.
+
Resolution of the entire issue on a single change order is ideal. This prevents someone from repeatedly coming back to request compensation for an item believed to be resolved with other items. The contractor is always paid what the engineer believes is owed. MoDOT will not be penalized for any delay in verifying or resolving disputes. <u>Never</u> <u>pay</u> any amount that is a compromise figure without including in the change order documentation the recommended language found near the bottom of EPG 113.2.1 Time-Related Disputes. Absence of this recommended language could impress a potential jury that the withheld amounts were held as undisputed hostage until the contractor capitulated on the remaining amount. Always be fair. If the contractors errantly do not request payment for something they are contractually owed, inquire why they did not. The goal is to pay what is contractually owed and not how little the issue can be resolved for. These good faith gestures will lead to a more timely resolution. This reduces time and expense for everyone and greatly reduces the likelihood that it will end up in litigation. Litigation is costly and time-consuming for all parties and should be a last resort.

Revision as of 14:38, 2 April 2020

113.jpg

Assure the contractor that project personnel are available and willing at all times to discuss and give decisions on all questions that may arise concerning interpretation of the plans and specifications. When agreement cannot be reached at the resident engineer level, inform the District Construction and Materials Engineer of the misunderstanding. If agreement cannot be reached at the district level, the disagreement should be referred to the State Construction and Materials Engineer, through the District Engineer. Personnel of Construction and Materials are available to attend any discussion of problems and assist in settlement of disagreements. If questions arise between the resident engineer and the contractor about established policy, design features or standardization of procedures, refer the matters to the District Construction and Materials Engineer for a decision. In all cases, immediately inform the contractor in writing of the final decision and that the problem may still be appealed to higher authority.

When it becomes evident that a claim will be filed, inform the district office at once and start preparation of a detailed record. The RE should thoroughly document all conversations and circumstances involving the dispute. Cover the situation in detail each day in the resident engineer's diary Bulldozer.jpg.

The following are guidelines that shall be followed by contractors in filing a claim with the Secretary of the Commission.

113.1 Procedures for Handling Contractor Claims

1. The claim is received by the Commission Secretary, logged in, and forwarded to Construction and Materials Division. The division is responsible for providing all required reports and other documents to the Claims Committee, which is comprised of the Asst. Chief Engineer - Chair, Chief Financial Officer, and a District Engineer appointed by the Asst. Chief Engineer.

113.1.jpg

2. CM Division reviews the claim for compliance with specifications and may consult with the Chief Counsel’s Office (CCO) regarding compliance with specifications relating to timely filing and sufficiency of the claim documents submitted.

The division provides a preliminary copy of the claim to the CCO and the Audits and Investigations Division (AI) to facilitate this review as a notice of issue and for informational purposes. CM will continue to evaluate if further evaluation is needed by AI or CCO. In all cases of federally funded projects, the Federal Highway Administration (FHWA) will be provided a copy of the claim and the letter to the contractor.

3. If the claim is accepted by the Commission, the division assigns a claim number (year, sequential number, district; example: 03-01-07) and assigns the claim to a claim reviewer (Reviewer) in the CM Division for review and evaluation. The claims reviewer is a Construction and Materials Liaison Engineer who has no previous extensive involvement with the issues presented in the claim. The liaison engineer’s goal is to provide an independent review of the facts and merit of the claim. The reviewer maintains all correspondence and documentation associated with the assigned claim.

CM Division advises the contractor by letter if the claim has been accepted and provides the contractor with the claim number and the reviewer’s name. If the claim is not accepted, CM Division advises the contractor by letter citing the reason(s) the claim was not accepted and provides a copy of the letter to the CCO and AI.

When notification of a claim is received the district personnel and Resident Engineers office should not discuss the claim with any outside parties. Any inquiries should be referred to the Chief Counsels office. All appropriate files, diaries, records, etc. should be assembled and stored in a safe location at the project office or district office.

4. Claims and controversies that qualify for Arbitration or Mediation (Sec 105) must complete the review process including final notification to the contractor within ninety days from date of receipt by the Commission Secretary. At that point the contractor is eligible to submit these issues to binding arbitration or mediation. For claims that exceed the amounts provided by the Arbitration and Mediation laws, the State Construction and Materials Engineer may extend the time for review in order to provide time to adequately review the claim. The review of these claims should not extend beyond twelve months.

5. The following time lines will apply to the normal claims process:

a) CM shall notify the contractor of acceptance or denial of the claim upon completion of a review.
The reviewer will meet with the contractor for the purposes of clarifying the claim and developing a better understanding of the contractor’s position regarding the claim. If required, a written request for the additional records will be made. If after this initial meeting with the contractor, the assigned reviewer determines there are grounds for a negotiated contract adjustment, the reviewer will obtain approval from the State Construction and Materials Engineer to proceed with the negotiations. This meeting should take place within 28 days of the acceptance of the claim.
b) CM prepares a letter to the district, furnishing two copies of the claim (one for the District Construction and Materials Engineer and one for the Resident Engineer) for investigation and requests the district report to be submitted by a specific date. The district is further advised to retain all project records. The district report is prepared by the District Construction and Materials Engineer in consultation with the Resident Engineer Office directly associated with the claim. For claims on projects that have not been finalized, no adjustments to disputed items or time for completion of the subject project may be made without prior agreement with the State Construction and Materials Engineer.
In concert, the district and resident engineer are to review the claim and provide both a report on the facts of the claim and a separate recommendation regarding settlement to the State Construction and Materials Engineer with 28 days of the date of acceptance of the claim.
c) The district will submit the District Report to the claims reviewer on or before the date set by the division. A maximum of 28 calendar days will be allowed from the date of the letter of acceptance to the contractor. The first part of the report contains a factual analysis of the claim with no recommendation regarding disposition. This report should answer the claim in the same order or format as presented by the contractor. This is so that each allegation and response can be compared side by side. All allegations made by the contractor should be responded to. The second part of the report is a recommendation regarding disposition of the individual items in the claim.
The reviewer will meet with the district to listen to their version of events after receiving the District Report. This meeting should be held after the contractor meeting. This should happen within 2 weeks after receiving the District Report.
d) The reviewer will discuss the amount and complexity of the claim with the attorney assigned by the CCO for preliminary advice on additional research or evaluation is needed before proceeding. The reviewer will submit the Division Report within two weeks after the meeting with the district.
e) The division final report prepared by the State Construction and Materials Engineer will be completed within 5 calendar days of receipt of the reviewer’s report. This report will be provided to the Claims Committee immediately upon completion.
f) The Claims Committee meeting will be scheduled by the claims reviewer once the Claims Committee has received the Division Report.
g) The contractor may have legal counsel present, but it is not required since this is not a legal proceeding. MoDOT will have someone from CCO present at the meeting. Their role is to advise the Claims Committed on the legal merits of the case. They will not be presenting or asking questions at the presentation. MoDOT personnel attending the claims committee meeting will be the reviewer, the State Construction and Materials Engineer, a representative(s) of the affected district (District Construction and Materials Engineer and /or Resident Engineer) and any other State Engineers that the Claims Committee Chair may deem necessary.
The contractor will present their case to the claims committee. In the presence of the contractor, the reviewer, and other personnel deemed necessary will make oral presentations. The contractor may ask questions after the oral presentation and present any additional information as they wish. The Claims Committee will evaluate the contractor’s information and the information presented by MoDOT’s representatives. The Claims Committee will then make a decision regarding disposition of the claim (acceptance, partial acceptance, denial or the need for further deliberation) on the day of the meeting. The contractor will be given the option to remain in the building while the Claims Committee deliberates privately and will be advised of the Claims Committee’s decision if the individual remains.
If the Claims Committee’s decision is to make an offer to resolve the contractor’s claim by negotiated contract adjustment, the reviewer and division engineer will determine the basis and amount of the proposed adjustment. If the Claims Committee approves the amount, the contractor will be advised by letter, prepared by the division, stating the basis and amount of the offered adjustment. If the Claims Committee decides to deny the claim or make a unilateral adjustment under the contract, the contractor will be advised by a letter prepared by the division. The Claims Committee Chair will sign each type of letter. Subject to Delegation of Authority limitations, noted in Commission policy, the claims committee may act upon concurrence of any two of the three member Claims Committee. The Claims Committee has 7 days from the date of the Claims Committee meeting to respond to the contractor with a final decision including any offer of a negotiated contract adjustment or directed equitable adjustment. The above letters will be reviewed by the CCO before mailing.

6. The Commission policy on settlement of claims will outline authorization levels.

7. Upon resolution of a claim that results in an award to the contractor, either by action of the Claims Committee, by court action, or by negotiating, the division will submit information to the FHWA, if federal participation is desired. The information to the FHWA shall be in accordance with Attachment “A”.

Attachment “A”, CONTRACT CLAIM PROCEDURES

A. Contract Disagreements
1. Contract disagreements which are resolved informally between a contractor and Missouri Department of Transportation project or district personnel should be submitted to the Federal Highway Administration in the form of a change order for non-certification acceptance projects. Change orders for certification acceptance projects should continue to be approved by the Missouri Department of Transportation.
2. The change order should provide sufficient detail for the Federal Highway Administration to determine that the settlement between the Missouri Department of Transportation and the contractor is justified.
B. Formal Claims
1. If federal-aid participation is desired in a contract claim payment, early coordination between the Federal Highway Administration and the Missouri Department of Transportation is required for all claims handled through the Missouri Department of Transportation Claims Committee, or court adjudication.
2. If federal-aid participation is desired in a contract claim settlement for either a certification acceptance or a non-certification acceptance project, the Missouri Department of Transportation should transmit a copy of the contract claim, the legal and contractual basis for the claim, an analysis of the merits of the claim, and the results of the Missouri Department of Transportation Claims Committee review to the Federal Highway Administration Division Office for review and approval.
3. The Missouri Department of Transportation’s request for federal-aid reimbursement on an adjudicated contract claim award should include an explanation of the legal and contractual basis for the claim, the cost data and other facts supporting the award, and an audit by ABA or an independent consultant of the actual costs incurred by the contractor. A legal opinion from counsel should accompany claims with complex or novel legal issues.

8. If the contractor provides written acceptance of the negotiated contract adjustment offer, Financial Services is notified of the amount with appropriate documentation and requested to process payment to the contractor. This completes the claim process.

9. If the contractor notifies the department that they do not accept the final negotiated contract adjustment offer, or if the contractor does not respond by the date given in the settlement offer letter, the claim will be closed and any unilateral adjustment determined appropriate will be made.

10. All notes and information gathered in the claims process are conducted in anticipation of litigation, to be privileged communications or work product of MoDOT’s or Commission’s representatives and shall also be considered government predecisional memoranda.

113.2 Dispute Resolution

The first step in resolving a contractor dispute is to gather information. The RE should sit down with the contractor and review all the information related to the dispute. Go in with an open mind. Too often people come into this meeting to defend their position instead of truly listening to the other person’s perspective. Resist the temptation to argue points of dispute at this meeting. The purpose of this meeting is to gather information and not to litigate the issue. This may sound basic, but it is invaluable when resolving conflicts because it helps to reveal the real issues.

113.2.1 Time-Related Disputes

If it is determined that there is time due to the contractor, then a method to determine the extent of time should be established. If it is a time delay, make sure the time adjustment is made immediately at the conclusion of the event that is being discussed. Do not wait until the end of the job to adjust days since contractors may be able to claim they incurred acceleration costs to complete the project by the original completion date. The time extension must be made by change order. Verbally telling the contractor is not binding and cannot be verified. A verbal commitment is not part of the official contract that the contractor must honor. Even if the contractor is ahead of schedule and will likely finish by the original completion date, the Resident Engineer will still need to write a change order for additional delays. Without a change order, the contractor may still claim acceleration costs.

Suppose there is a hard commitment on a deadline that cannot be moved. If this is the case, compensation to accelerate the project must be negotiated. If that amount cannot initially be agreed upon, then an agreement on what is compensable should be established, as well as a mechanism to track it. Once again, regardless of where contractors may be on their schedule, they will need to be compensated for acceleration to make up the days that are owed by contract if it really occurred. Do not pay for acceleration unless increases in premium time or other unforced increases in cost can be proven.

Time extensions may also affect any milestones that are on a project. These may need to be adjusted accordingly.

Delays caused by utilities are generally excusable but never compensable. Simply stated, additional time can be allotted, but not additional money. Other delays such as plan errors, differing site conditions, etc. could be compensable. Extended delays may result in higher costs to the contractor. Examples are labor increases, material cost increases, extended traffic control maintenance, equipment rental costs and jobsite office expenses. These delay costs can be extensive, especially on large-scale projects with high overhead and long periods of delays. A delay may push a job into winter or other time periods where critical path work cannot be performed or productivity rates are lower. Besides requiring additional time, this can also lead to additional costs incurred related to the delay periods.

The important thing is to research and determine whether the delay really did result in costs. Only verifiable, auditable costs should be considered.

Delays are very costly. A quick resolution to issues causing the delay is the best way to insulate a project from a large delay claim. Paying a premium to mitigate a delay impact will likely be a better value than paying for a delay claim. When a change order involves settlement and final resolution of an issue with the contractor or when there are concerns that the issue may come up again in a claim or lawsuit, the following language is recommended as part of the change order documentation:

"The amount being paid to <Construction Company> in this Change Order represents a negotiated settlement and, as such, reflects payment of all claims of <Construction Company> and/or any of its subcontractors and suppliers direct and indirect, including all impacts therefrom starting from the date of execution of the contract until the execution by both parties of the Change Order. However, nothing in this Change Order affects <Construction Company>'s right to file a claim based on an occurrence after the date of this Change Order."

Note: Do not include the last sentence if the change order is final.

113.2.2 Compensation Disputes

If there is compensation due and agreed upon, a change order should be issued immediately. Any delay in payment could be subject to interest owed the contractor as a part of the Prompt Pay Act, RSMo 34.057 (which does not apply if there is a genuine dispute as to causation or amount). If there appears to be a pay dispute, begin keeping thorough records of labor, equipment and materials. It is very difficult to quantify this information after the fact.

Resolution of the entire issue on a single change order is ideal. This prevents someone from repeatedly coming back to request compensation for an item believed to be resolved with other items. The contractor is always paid what the engineer believes is owed. MoDOT will not be penalized for any delay in verifying or resolving disputes. Never pay any amount that is a compromise figure without including in the change order documentation the recommended language found near the bottom of EPG 113.2.1 Time-Related Disputes. Absence of this recommended language could impress a potential jury that the withheld amounts were held as undisputed hostage until the contractor capitulated on the remaining amount. Always be fair. If the contractors errantly do not request payment for something they are contractually owed, inquire why they did not. The goal is to pay what is contractually owed and not how little the issue can be resolved for. These good faith gestures will lead to a more timely resolution. This reduces time and expense for everyone and greatly reduces the likelihood that it will end up in litigation. Litigation is costly and time-consuming for all parties and should be a last resort.